Martha Woodley Service Agreement


Logo

SERVICE AGREEMENT


This agreement is made and effective this (MM/DD/YY),

BETWEEN: (the "Client"), a corporation with an address at:



AND: Rank Above Others, Inc (the "Provider"), a corporation organized and existing under the laws of the Texas, with its head office located at:

500 N Shoreline Blvd
Suite 706
Corpus Christi, TX 78401

1. OVERVIEW

AspirationsWork is on a mission to address the chronic shortage of housing and provide available options for renting in an affordable community. Located in Georgetown, Texas with its primary service focused on developing communities, creating change, and impacting lives by providing safe and affordable housing to homeless Veterans and low-income families. Offering supportive services for resources to healthcare, substance abuse, and mental health counseling for Veterans. Transitional housing for Veterans discharging from residential treatment programs. Client requires a modern and professional website that will appeal to the target audience while providing great efficiency for both users and staff. 

  1. Provider will deliver a Premier Business Website – This is a great choice for businesses needing help getting started online and have no time to waste. You'll be able to choose a theme from our gallery and use exactly that. A new logo will be created for your company and a slider graphic will be provided to reflect your business services/products. Included in this service is also the creation of up to 7 pages; I.E. Home, About, Services, Contact, Gallery, etc. Content must be provided in a text document, PDF or via our project management system directly. We can add up to 2 submission forms, including a contact form and even include a map on your contact page. This does not come with any mockups or drafts. If you need more work done to your website, please consider our Advanced Website service or the customization services. After that, any additional work will be recorded in our "whatever hours." You will have 2 WH.
  2. Provider will deliver a business card design and print 500 matte. Complete front and back design of standard business cards printed on 500, 14pt matte or glossy finished cards. extra $10.00 for 16pt glossy and extra $15.00 for 16pt matte. Shipping is included.

A demo site will be provided to Client for review and approval before going live. Client will gain access directly to the website before going live so that additional changes can be made directly by Client.

 

2. FEE SUMMARY

Service

Days

ONCE

MONTHLY

Web Design 

 

 

 

Premier Business Website

 9-12

 $950.00

 $0

Print 

     

Business Card Design and Print 500 Matte

9-12

85.00

$0

Sub-Total

 

$1035.00

 

3. FINANCIAL TERMS

Provider will provide such services to Client upon the terms and subject to the conditions hereinafter contained below. Any web design and web development projects exceeding $5,000 are available for the milestone payment process. All projects under $5,000 require a full payment via check or wire transfer made out to Provider’s details indicated on page 1 of this agreement.

Other charges (if applicable): All additional work outside of project scope is billed hourly based on the type of service required. The following are rates for such services: content curation - $100/hr, graphic design - $120/hr, developmental coding - $180/hr, troubleshooting - $200/hr. These charges are billed at the end of the month.

4. AGREEMENT FOR SERVICES

For the avoidance of any doubt, it is hereby stated that the parties intend and agree that this Agreement shall be treated for all purposes as an agreement for contracted services between the parties, and it does not create an employer and employee relationship. Unless failure to deliver services rendered by Provider, there are no refunds whatsoever due to time, energy and expertise utilized to develop, deliver or provide new content and other intellectual property on Client’s behalf. Service(s) may be canceled, but not refunded.

5. DELIVERY DATE

Client will not hold Provider accountable to the estimated delivery date due to circumstances such as additional requests, changes/implementation or delays caused by Client response or payment. Reasonable delays may occur unexpectedly and extended completion dates will not be a violation of this agreement nor terms of termination. Client may still cancel the project at any time but will not be due for a refund on payments made up to that date.

6. CONFIDENTIALITY

Provider recognizes and acknowledges that the leads, clients, software systems, including specifications, programs and documentation, the methods and data which Client owns, plans or develops, whether for its own use or for use by its clients, developments, designs, inventions and improvements, trade secrets and works of authorship are confidential and are the property of Client. Provider also recognizes that Client's customer lists, supplier lists, proposals and procedures are confidential and are the property of Client. Provider further recognizes and acknowledges that in order to enable Client to perform services for its clients, those clients may furnish to Client confidential information concerning their business affairs, property, methods of operation or other data; that the goodwill afforded to Client depends upon, among other things, Client and its Providers keeping such services and information confidential. All of these materials and information including that relating to Client's systems and Client's clients, will be referred to below as "Proprietary Information."

7. NON-DISCLOSURE

Provider agrees that, except as directed by Client, and in the ordinary course of Client's business, Provider will not at any time, whether during or after Provider's employment with Client, disclose to any person or use, directly or indirectly, for Provider's own benefit or the benefit of others, any Proprietary Information, or permit any person to examine or make copies of any documents which may contain or is derived from Proprietary Information, whether prepared by Provider or otherwise coming into Provider's possession or control. Provider agrees that the provisions of this paragraph shall survive the termination of this Agreement.

8. POSSESSION

Upon request, Provider shall promptly deliver to Client any and all Property of Client including Property in the possession or control of Provider's employees, services providers, affiliates and contractors. All copies of materials or software obtained from Client shall be either returned to Client or permanently deleted at Client's direction. 

9. OWNERSHIP

Provider hereby assigns and agrees to assign to Client or its subsidiaries or affiliates, as appropriate, its successors, assigns or nominees, Provider's entire right, title and interest in any developments, designs, patents, inventions and improvements, trade secrets, trademarks, copyrightable subject matter or proprietary information which Provider has made or conceived, or may make or conceive, either solely or jointly with others, while providing services to Client, or with the use of the time, material or facilities of Client or relating to any actual or anticipated business, research, development, product, service or activity of Client known to Provider while employed at Client, or suggested by or resulting from any task assigned to Provider or work performed by Provider for or on behalf of Client, whether or not such work was performed prior to the date of this Agreement.

10. NON-COMPETITION

Provider agrees that because of the confidential and sensitive nature of the Proprietary Information and because the personal use of, or even the appearance of the personal use of, the Proprietary Information in certain circumstances may cause irreparable damage to Client and its reputation, or to clients of Client, Provider shall not, until the expiration of 2 years after the date on which Provider's employment with Client terminates for any reason, engage, directly or indirectly, or through any corporation or associates in any business, enterprise or employment which directly solicits business, performs services or delivers goods that are competitive to those of Client to any customer or prospect of Client.

11. INJUNCTIVE RELIEF

Provider acknowledges that disclosure or personal use of any Proprietary Information by Provider or breach by Provider of any of the covenants will give rise to irreparable injury to Client, or clients of Client. Provider also agrees that this injury to Client, or clients of Client, would be inadequately compensated in money damages alone. Accordingly, Client or, where appropriate the client of Client, may seek and obtain injunctive relief against the breach, or threatened breach, of the disclosure or personal use of any Proprietary Information by Provider, in addition to any other legal remedies which may be available. Client further acknowledges that the enforcement of a remedy hereunder by way of injunction would not prevent Provider from earning a reasonable livelihood since Provider's experience and capabilities would be such that in the event that Provider's employment with Client terminates for any reason, Provider will be able to obtain employment in business activities which are not restricted by this Agreement.

12. INDEMNIFICATION

Client and Provider agree to hold the other party harmless from all losses, liabilities, damages, cost and expenses (including reasonable attorney's fees), arising from the enforcement of this agreement.

13. GENERAL

This Agreement contains the entire understanding between Client and Provider relating to the subject matter of confidentiality, work product and non-competition. This Agreement shall be governed by and construed in accordance with the laws of Texas, and may be modified only by a writing signed by Provider and Client. Provider hereby consents to the exclusive jurisdiction of the courts of the United States sitting in Texas. The provisions of this Agreement relating to confidentiality and non-competition shall survive any termination of service no less than two years from the date of termination. 


IN WITNESS HEREOF, each party to this Agreement has caused it to be executed on the date indicated above.

 

CLIENT PROVIDER

Leave this empty:

Signature arrow sign here

Signed by Van Lam
Signed On: May 2, 2023


Signature Certificate
Document name: Martha Woodley Service Agreement
lock iconUnique Document ID: 421afaecbcea28015c2bf579c809f947e9b01374
Timestamp Audit
May 24, 2022 2:45 pm CDTMartha Woodley Service Agreement Uploaded by Van Lam - kevin@rankaboveothers.com IP 112.198.95.126